Abstract
The FIDIC concept of Time for Completion is based on Clause 8 FIDIC Conditions. According to this concept the parties agree on a period of time for completion, which is usually indicated in the Appendix to Tender (Yellow Book, Red Book), in the Particular Conditions (Silver Book) or the Contract Data (Gold Book). Time for completion starts when the Engineer has notified the Commencement Date, which he shall do within 42 days after the Contract has been executed by a seven days’ notice (14 days under the Gold Book). Subject to Sub-Clause 1.1.3.3 Time for Completion means the time for completing the Works or a Section (as the case may be) under Sub-Clause 8.2, as stated in the Appendix to Tender or the Particular Conditions (with any extension under Sub-Clause 8.4, calculated from the Commencement Date). According to Sub-Clause 8.2 the Contractor shall complete the whole of the Works within the Time for Completion for the Works including completing all work which is stated in the Contract as being required for the Works or Section to be considered to be completed for the purposes of taking-over under Sub-Clause 10.1. In other words, the Contractor complies with the requirements for Time for Completion if he completes the Works within Time for Completion until the issue of the Taking Over Certificate.
Access this chapter
Tax calculation will be finalised at checkout
Purchases are for personal use only
Notes
- 1.
[1999] NTSC 143; (2005) 21 Const. LJ 71.
- 2.
See Multiplex Constructions (UK) Ltd v. Honeywell Control Systems Ltd (No. 2) [2007] EWHC 447 (TCC).
- 3.
[2002] NSWCA 211, the New South Wales Court of Appeal.
- 4.
[2003] SLT 885.
- 5.
Multiplex Constructions (UK) Ltd v. Honeywell Control Systems Ltd (No. 2) [2007] EWHC 447 (TCC).
- 6.
Alfred McAlpine Capital Projects Ltd v. Tilebox Ltd [2005] BLR 271 TCC.
- 7.
Hind Construction Contractors v. The State of Maharashtra [1979] AIR 720, 1979 (2) SCR1147, 1979 (2) SCC 70.
- 8.
Hind Construction Contractors v. The State of Maharashtra [1979] AIR 720, 1979 (2) SCR1147, 1979 (2) SCC 70; see also Shambhulal Pannalal, Secretary of State [1940] AIR Sind I.
- 9.
Mohinder Singh and Co v. Executive Engineer, CPWD, [1971] AIR J&K 130.
- 10.
State of Rajasthan v. Chandra Mehan [1971] AIR, Raj. 229.
- 11.
Ramnath International Construction Pvt. Ltd v. Union of India 2007 AIR 509, 2006 (10) Suppl. SCR 570, 2007 (2) SCC4 53, 2006 (14) SCALE 49.
- 12.
OLG Celle [2000] IBR 245.
- 13.
OLG Hamm [1996] IBR 509.
- 14.
BGH [1993] IBR 368.
- 15.
OLG [2002] IBR 542.
- 16.
See Schulze-Hagen [2001] IBR 165.
- 17.
OLG Koblenz [2000] IBR 535.
- 18.
OLG Hamm [2000] IBR 489.
- 19.
Pursuant to UCA 63-56-601 and Utah Administrative Code Rule R23-1-60.
- 20.
[1982] 1 WLR 794, at 801.
- 21.
(1993) 62 BLR 1, at 25 (concerning a JCT contract).
- 22.
(1999) 70 Con LR 32.
- 23.
December 2007; file no. VII ZR 28/07.
- 24.
OLG Zweibrücken [2006] IBR 246.
- 25.
BGH [2002] IBR 354; BGH [2005] IBR 246.
- 26.
KG Berlin [2003] IBR 67, further appeal to the Federal Court of Justice dismissed.
- 27.
BGH [1993] BauR 600, at 603.
- 28.
December 2007; file no. VII ZR 28/07.
- 29.
Mitchell Engineering & Construction Co, Inc, ENG BCA No. 3785, 89-2 BCA 21, 753.
- 30.
Engineered Electric, ENG BCA No. 4944, 84-2 BCA 17, 316.
- 31.
Breas of Doune Wind Farm (Scotland) Ltd v. Alfred McAlpine Business Services Ltd [2008] EWHC 426 (TCC) per Akenhead J.
References
Kappellmann K, Schiffers K-H (2006) Vergütung, Nachträge und Behinderungsfolgen beim Bauvertrag, vol. 1, 5th Edition. Werner, Köln
Patil (2005) Building and Engineering Contracts, 5th Edition, Patil, Pune
Werner U, Pastor W (2008) Der Bauprozess, 12th Edition. Werner, Köln
Author information
Authors and Affiliations
Corresponding author
Rights and permissions
Copyright information
© 2009 Springer-Verlag Berlin Heidelberg
About this chapter
Cite this chapter
Jaeger, AV., Hök, GS. (2009). Time for Completion. In: FIDIC - A Guide for Practitioners. Springer, Berlin, Heidelberg. https://doi.org/10.1007/978-3-642-02100-8_12
Download citation
DOI: https://doi.org/10.1007/978-3-642-02100-8_12
Published:
Publisher Name: Springer, Berlin, Heidelberg
Print ISBN: 978-3-642-02099-5
Online ISBN: 978-3-642-02100-8
eBook Packages: Humanities, Social Sciences and LawLaw and Criminology (R0)